1. General conditions (v2019.001)
1.1. BASIC CONDITIONS
The provisions of these general conditions are subdivided into basic conditions which are applicable to every agreement between EASI and the customer, irrespective of the subject, and specific conditions which are applicable depending on the subject of the contract. The basic conditions are set out in heading 1 and the specific conditions are set out in headings 3 and following. The provisions in heading 1 apply to all of the cases mentioned in headings 3 and following.
These general conditions apply to the exclusion of all other general conditions. By ordering from EASI, the customer irrevocably accepts the application of these general conditions, to the exclusion of all others, and may not be exempted therefrom except by special conditions set out in a written document bearing the signature of a person duly authorised to represent EASI. In the event that the customer's purchase conditions are accepted in writing by EASI, these conditions shall prevail over EASI's own general and sales conditions. EASI's general and sales conditions shall still apply for any points not covered in the customer's purchase conditions.
The provisions of the contract signed between EASI and the customer annuls and replaces all other terms, conditions, agreements or stipulations, correspondence and/or previous agreements. These provisions and documents may not be modified, deleted or supplemented, in whole or in part, except through the written agreement of EASI and its customer. Any subsequent version of these general conditions shall, however, be considered as having been irrevocably accepted by the customer where the customer does not express its refusal thereof within one month of the date on which the general conditions were sent to the customer by EASI.
In the event that the customer cancels their order, whether before or in the process of execution, EASI may require the forced execution of the contract, or seek payment of damages and interest.
This will include, in particular, and without this list being exhaustive, (1) the cost of supplies already ordered by EASI with a view to their delivery to the customer, (2) the other costs incurred by EASI and the fees due to it for services rendered up to the date of cancellation of the order or termination of the contract and, (3) an indemnity for loss of income equivalent to 50% of the other amounts which EASI could have invoiced to the customer in the event that the contract had been executed until completed.
The contract shall, moreover, be terminated ipso jure in the case of the bankruptcy of either party, and in the case of judicial reorganisation if the customer has not ended its breach within a period of fifteen days following formal notification thereof by EASI.
Our offers are valid for 3 months from the date on which they are sent, unless otherwise specified; offers for hardware and software (not designed by EASI) are valid for 2 weeks from the date on which they are sent. All the amounts specified in the offers exclude VAT. EASI’s invoices are payable within ten days of their date of issue and without discount. Any invoice not contested by the customer in writing to EASI within fifteen days of the date of its issue is considered as having been definitively and irrevocably accepted. Any invoice which is not paid by its due date shall be increased ipso jure and without formal notice by interest at 6% over the legal rate and a fixed indemnity equivalent to 15% of the amount invoiced, with a minimum charge of €200. In the event of non-payment of an invoice by its due date, EASI shall be, moreover, authorised ipso jure and without formal notice to suspend the execution of all deliveries and services until the date of payment, and this without prejudice to the customer’s obligation to fulfil its commitments. In the event of non-payment of an invoice within a period of fifteen days following a formal notice, EASI shall have the right to deem the contract terminated by the fault of the customer, and to require him to make payment of an indemnity calculated in accordance with article 4.
Associated costs are never part of fixed prices and, as a consequence, are invoiced by EASI to the customer. Associated costs mean the travel, parking and accommodation costs of EASI staff. Travel costs in Belgium and the Grand Duchy of Luxembourg, including related travel time, are calculated on the basis of €0.95 per kilometre, with a minimum of €95 from the time the contract is signed. Travel costs are indexed annually on 1st January based on the consumer price index, the basic index being that of the month of November 2013 and the new index being that of the month of November before the change. Non-indexation on the annual date agreed shall not imply any waiver of its application during the year or on later annual dates. Travel costs outside of Belgium and the Grand Duchy of Luxembourg shall be agreed with the customer in special conditions.
The deadlines for the delivery of supplies or execution of services set out in the contract between EASI and its customer are given purely for information, and their being exceeded may not give rise to any indemnity or to the termination or cancellation of the contract. When a compulsory deadline is given in the contract, the customer may not seek the termination or cancellation thereof until it has formally notified EASI that it must execute its obligations within a reasonable period which is appropriate to the circumstance, it being understood that no indemnity may be claimed by the customer from EASI if the latter executes its obligations within the aforesaid reasonable period. The deadline shall be considered compulsory only where the relative contractual clause in the special conditions expressly specifies and in these terms, to the exclusion of all others, that the deadline is compulsory.
EASI shall not be liable for any damage resulting from a breach, or, when a compulsory deadline has been agreed, from a delay in the execution of its contractual obligations, if the reason for this breach or delay cannot be attributed to it, as, for example, in the case of government action, force majeure, war, riots, strike or breach by its own suppliers. On the assumption that EASI is required to pay damage and interest, these shall only include direct damages and not potential indirect damages such as, in particular, loss of income, increase in general costs and schedule disruption as well as loss of profits, customer base or savings expected by the customer. In any case, any damages and interest which may possibly be due by EASI to the customer shall not exceed 50% of the fixed price set out in the contract, with the exclusion of standard hardware and software not developed by EASI.
EASI and the customer are required to maintain the confidential nature of all information communicated in the context of the negotiation and execution of the contract concluded between them, in particular information regarding their production, organisation and working methods. They hereby undertake not to divulge any of this information without the written agreement of the other party. They shall divulge information only to their employees who are directly involved in the execution of the contract, or making use of the programs, and they hereby guarantee that these employees are aware and will comply with the obligations in relation to the confidential nature of the said information.
The customer may not, under any circumstances, without the prior written agreement of EASI, assign, in whole or in part, to one or more third parties, the rights and obligations resulting from the contract agreed between the customer and EASI. Any assignment done without the prior written agreement of EASI shall remove EASI from the requirement to execute the contract. EASI may assign all its rights and obligations arising for from this contract through simple notification of such assignment to the customer. The customer may, in this case, end the contract by giving the relevant contractual notice.
A customer for whom EASI has executed, or is executing, a service, hereby undertakes not to recruit, or to outsource services to, directly or indirectly, under any contract or agreement whatsoever, personally or by an intermediary natural person or legal entity, a member of staff of EASI (and of all the companies belonging to the same group) or to its subcontractors, whether the customer has been in contact with him or her or not. A member of staff of EASI or its subcontractors means anyone who is currently, or has previously been, active in this capacity. This undertaking must be adhered to by the customer both during the execution of the contract and for a period of three years starting at the date of the end of contractual relations between EASI and the customer and/or for a period of one year starting at the date of the end of contractual relations between EASI and its employee and/or sub-contractor. In the event of failure to comply with this undertaking, the customer shall be liable to pay EASI an indemnity equivalent to twenty-four times the monthly cost incurred by EASI for the services of its departing employee or sub-contractor, the monthly cost being fixed by reference to the average of the months, not exceeding one year, preceding the end of contractual relations between EASI, on the one hand, and its employee or sub-contractor on the other hand. This indemnity is fixed without prejudice to the possibility of EASI claiming payment of other amounts, on the assumption that its damages are higher.
Nullity of one of the contractual clauses applicable between EASI and the customer shall not affect the validity of the other clauses.
Any dispute in relation to the validity, interpretation, execution or termination of the contract agreed between EASI and its customer shall come within the exclusive competence of the Courts of the registered office of EASI. EASI shall, however, have the right to summon the customer before the Court of its registered office or, in the case of the service of third-party notice, before the Court responsible for the principal action.
1.2. STANDARD HARDWARE AND SOFTWARE NOT DEVELOPED BY EASI
Title 1.2 covers the computer hardware equipment sold by EASI to the customer, and the standard software not developed by EASI, supplied by it to the customer and in respect of which EASI acts as a simple intermediary.
The customer hereby declares having received, from EASI, all the information which will allow it to make an informed choice, particularly as regards the adequacy between its concrete requirements and the computer equipment and standard software it has ordered. The customer renounces, as a consequence, the right to introduce any claim of any kind against EASI in the hypothesis where it is subsequently proved that the computer equipment and standard software supplied do not meet some of its requirements, unless they had been precisely defined in advance in the order, or in any set of specifications.
The cost of the installation of the computer equipment and the standard software are not included in the price agreed for their supply. In the absence of a special agreement these costs will be invoiced for settlement at the rate applied by EASI for such services.
The ownership of the computer equipment, support for standard software and the right of use thereof are not transferred to the customer until the corresponding invoices are paid in full. EASI shall consequently remain the owner of the equipment and support delivered and the sole owner of the rights to use the standard software supplied, until such time as this full payment is made. Prior to delivery of the computer equipment, the customer is required to forward, in writing, to EASI, the address and telephone number of the lessor of the premises in which this equipment is to be installed, together with the address and telephone numbers of any creditor who may have a security on its business, EASI having the right to suspend all deliveries until this information is obtained. EASI is authorised to make contact with the lessor and the creditors to notify them that it remains the owner of the goods delivered until paid in full. For as long as the customer is not the owner of the equipment delivered, the customer may not assign it, or make it available to third parties in any way, or give it as security, without advance and written approval from EASI. Moreover, and still under the same assumption, the customer shall advise EASI within twenty-four hours of any seizure of the equipment delivered or any other claims of any kind made by third parties against all or part thereof.
The computer equipment and software not developed by EASI are invoiced at 100% on ordering. Delivery costs and Recupel, Auvibel, Bebat or Reprobel taxes are also invoiced. For any order lower than €1,000.00 an amount of €100.00 will be invoiced for administrative costs. Any intervention by EASI for ‘defect’ problems (equipment breakdown, system errors or software errors – IBM Notes, Microsoft SQL etc.) or ‘non-defect’ problems (incorrect use) will be invoiced to the customer at the rate in effect.
The customer is required, on delivery of the goods it ordered, to verify that these goods, and their packaging, show no signs of damage. If some of the goods are found to be damaged, the customer is required to refuse delivery thereof by the carrier, failing which the goods shall be considered to be delivered in good condition, without the right to claim against EASI. The customer shall also, on delivery, verify that the packages delivered match the packages listed on the consignment note or packaging list, it being understood in the absence of a formal note in writing on this point to the carrier at the time of delivery, all the packages listed in these documents shall be considered as having been delivered, without the right to claim against EASI.
After delivery of the goods, the customer is required to quickly make a more in-depth examination of them, with a view to detecting any possible apparent defects which could not reasonably be found by opening the packages during delivery. The customer shall inform EASI, in writing, within eight calendar days of delivery, of any apparent defects so discovered following the delivery. The absence of any claim within this period shall be deemed as approval of the goods delivered and renunciation of the right to claim for any apparent defect.
In the event that hidden defects or malfunctions affecting the goods delivered are discovered subsequent to their installation, the customer shall advise EASI thereof, in writing, within forty-eight hours of discovery, providing as many details as possible regarding the nature of the defect or malfunction found. EASI shall be required to fulfil the guarantee in accordance with terms and conditions similar to those of the guarantee that it itself holds from its supplier, the terms and conditions of which are known to the customer. Subject to the limits set by the preceding sub-paragraph, the contractual guarantee granted by EASI shall apply for a period of three months from the date of delivery of the goods, or if the installation thereof was entrusted to EASI, from the date thereof. After this period of three months, the manufacturer's warranty will apply according to European legislation.
In the event that a defect or malfunction is discovered, the customer shall cease all use, manipulation, implementation and/or installation of the goods supplied. It shall provide any assistance necessary in relation to the examination of the claim made. If the customer does not provide such assistance, or if, for any reason which may not be ascribed to EASI, examination of the claim made is not or is no longer possible, it shall be refused, without the customer having the right to claim against EASI. If the claims made are not founded, the fees and the costs of the services resulting therefrom shall be invoiced by EASI to the customer. EASI shall not be required to fulfil the guarantee, (1) if the debts owed to it by the customer have not been paid in full, (2) if the customer has had a third party make, or has made changes, adaptations or repairs to the goods delivered, (3) if it has used the goods for other purposes or on another basis to that for which they were designed, (4) if they have been subject to inappropriate treatment or servicing. The guarantee does not cover damage and malfunctions which do not constitute manufacturing defects and, in particular those which can be attributed to (1) errors and negligence by the customer in relation to the protection, use and/or maintenance of the equipment, (2) the electrical installation or supply of electrical current, (3) moving the goods, (4) and all other accidental causes such as an accidental fire or water leak.
As the guarantee consists only of the repair or exchange of parts recognised as defective in accordance with the conditions set out in article 19, the services provided by EASI with a view to solving the problems found, whatever they may be, shall be invoiced to the customer for settlement, at the rate in effect. On the assumption that the call on the guarantee is justified, the services provided by EASI shall not be invoiced if it had been contractually responsible for the installation and commissioning of the goods supplied and if the problems found are the result of an action which may be attributed to EASI.
The customer has been informed of the fact that EASI is acting only as an intermediary for the maintenance of computer equipment and standard software not developed by it.
1.3. STANDARD APPLICATIONS OR SOFTWARE DEVELOPED BY EASI
The provisions of heading 1.3 apply to standard software as well as standard applications for mobile devices (smartphones, tablets etc.) or parts of this software and these applications, developed by EASI with a view being offered to all of its customers and the adaptation of which to the specific requirements of each customer does not require additional analysis (with a view to programming work) or programming work. This software and these applications are described hereafter as "software packages" or "applications". They may either be purchased or rented by the customer and used in either the customer's infrastructure or the Cloud2be environment specified in heading H of these general conditions. The installation of the software package in a shared Cloud environment other than the Cloud2be environment, or another environment for which EASI is responsible, is not authorised.
EASI grants the customer a limited right to use the software package under licence covered by the special agreement made between them, it being understood that this, including its media, remain the exclusive property of EASI. As the right to use granted to the customer is limited, the following actions are formally prohibited, unless they are necessary to allow the customer to use the software package under licence in a manner which conforms with its purpose:
- the correction of errors without the intervention of EASI.
- the permanent or temporary reproduction of the software package under licence, in whole or in part, by any means or in any form of any kind. When the loading, display, transfer, transmission or storage of the software package under licence requires such reproduction, these actions shall be submitted for the prior written approval of EASI.
- any operation or handling that enables use of the software package under licence by a number of users which exceeds that specified by the special conditions.
- the translation, adaptation, arrangement and all other transformations of the software package under licence, and any reproductions resulting therefrom.
- any form of distribution to the public, including renting and lending, of the original of the software package under licence, or copies thereof.
- All forms of distribution to parent or sister companies of the customer. The customer may, however, after written agreement from EASI, allow the use of the software package to these daughter companies of which he has a participation of at least 51%.
On the other hand, the reproduction of the software package under licence in the form of a saved copy is authorised, and solely for the requirements of this saved copy, without the reproduction being used for other purposes. The right to use the software package under licence shall not in any case be assigned in any form or for any reason of any kind. The customer shall be liable to pay EASI, for each action committed in violation of any of the provisions of this article, for a purchased software package, compensation equivalent to double the updated sale price of the software package and, for a rented software package, compensation equivalent to 48 months of rental charges, with a minimum of €50,000.
The methods, models, descriptions, calculations and specifications in relation to the software package, together with its sources, remain the exclusive property of EASI and are not made available to the customer. EASI therefore remains the sole owner of all the intellectual rights directly or indirectly associated therewith. At the request of the customer, EASI undertakes, however, to lodge the source code of the software package covered by their special agreements with a third party acting as a trustee and authorised to issue the source code to the customer in the following cases only:
- EASI states to the customer that the software is no longer commercially pursued and that it will no longer provide its maintenance.
- the dissolution, excluding the merger, absorption or break-up of EASI, or insolvency thereof, unless the rights and obligations existing on the part of EASI in relation to the software package concerned are assigned to a third party by the liquidator or trustee of EASI within three months of its dissolution or insolvency.
The costs generated by the lodging of the source code of the software package with a trustee shall be invoiced by the latter directly to the customer. EASI shall, moreover, invoice the customer for the costs and services generated by the lodgement, particularly those for the preparation of magnetic storage media.
In compensation for the right to use the software package, the customer shall be required to pay EASI a single fee for a purchased software package or a periodic fee for a rented software package.
For purchasing, the fee is payable on the basis of 90% on ordering and 10% on final acceptance. The portion for acceptance will be invoiced at the latest twelve months after the order if acceptance is not carried out for reasons attributable to the customer.
For renting, the minimum rental period is two years and the fee is due in advance at the intervals set out in the special conditions. The period covered by the first fee instalment shall start (I) on the first day of the month following the effective start-up of the software package by a systematic encoding of data or by the ongoing operational use arising from the performance of simple, one-off tests, (2) in the absence of such effective start-up, the first day of the fourth month following the project launch (Kick-off) meeting, and (3) in any case, at the latest following a period of six months from the date of the order. Where the rental contract is not terminated by means of registered letter sent by one party to the other party three months before the end of the initial rental period, the rental contract shall be renewed for successive periods equivalent to that of this initial period. Each party shall be entitled to terminate the contract at the end of each renewal period by means of notification by letter sent by it to the other party three months before the end of the rental period. The customer may notify EASI of its decision to reduce the number of users authorised by the rental contract by means of registered letter sent to EASI three months before the end of the period covered by the periodic fee specified in the special conditions. This is subject to the strict requirement that the reduction involves fewer than 50% of the number of authorised users; the number of users will therefore be adjusted at the time of invoicing for the periodic fee covering the following period. The rental fee shall be indexed on the 1st January of each year based on the consumer price index, the basic index being that of the month of November before the calendar year in which the software package was installed, the new index being that of the month of November before adaptation.
Every agreement in relation to the granting of a right to use a software package shall be terminated ipso jure in the event of the dissolution or bankruptcy of the customer.
In the case where the customer fails to comply with an obligation for which it is responsible, in particular the case of non-payment of a licence fee or maintenance invoice by the due date, or in the case of violation of one of the provisions of article 23, its right to use the software shall be automatically suspended on the date of issue of a formal notice by EASI. If the customer does not fulfil its obligations within fifteen days of formal notification sent by EASI, the later shall have the right to deem contract termination by the fault of the customer, to suspend or remove the right to use the software package by the customer and to require the immediate return of the software package and its media, all without prejudice to damages which it shall also be authorised to claim.
Finally, the contract shall also be terminated in the event that the software package cannot be installed or used due to incompatibility between it and the customer’s hardware computer equipment or software as described to EASI when ordering. In this case, the termination of the contract for the provision of the software contract shall occur without damages on either side, except in the event that erroneous information had been communicated to EASI and in the event that the cause of the incompatibility is due to an action which can be attributed to the customer and which occurred subsequent to ordering. In any case, the costs incurred by EASI and the services executed by it in attempting to carry out the installation of the software package ordered shall be invoiced by EASI to the customer for settlement, at the rate in effect.
The customer hereby declares having received all the information in relation to the capacities and limits of the software package and that it is assured that it fulfils the use which the customer intends to make of it. EASI guarantees that the software package conforms, in all its essential elements, to the description which the customer acknowledges having received. The customer accepts that the software package may be perfectible and that possible adaptations or corrections aimed at ensuring its improvement are covered by the maintenance contract.
The customer shall have a period of one month, from the date of delivery, or the date of installation if this is entrusted to EASI, to make tests to ensure that the software package conforms in all its essential elements to the description thereof which was given to the customer. The customer shall devote the time and the means required to perform these tests within the aforementioned period, ensuring that the conditions under which the tests are performed are similar in all ways to those under which the software package will be used, including in relation to the number of users and the quantity and type of operations. In the absence of any written observation within the aforementioned period, or in the case of the starting of the software by a transfer or systematic encoding of data, or by on-going operational use resulting from the making of simple ad hoc tests, the software package shall be irrevocably considered as being definitively accepted by the customer.
If the customer discovers the presence of anomalies during the test period, it shall advise EASI thereof in writing and in a precise manner, as they are discovered. At the end of the test period, EASI and the customer shall draw up, at the first request of either, a provisional acceptance report of the software package indicating the anomalies to be solved, it being understood that no other anomaly existing at the date of drafting of this report and not indicated therein can be subsequently cited by the customer to refuse final acceptance. In the event that the customer refuses to carry out the drafting of the provisional acceptance report on one of the dates proposed by EASI, the software package shall be irrevocably considered to be finally accepted by the customer, even if anomalies were notified during the test period.
Final acceptance shall be given by the customer as soon as all the anomalies described in the provisional acceptance report have been resolved, it being understood that the transfer or systematic encoding of data, or on-going operational use of the software package by the customer, notwithstanding the fact that each of the aforementioned anomalies have not been resolved, means final acceptance and involves the obligation for the customer to pay EASI the full amount remaining due. In this event, the anomalies described in the provisional acceptance report, and which are not yet resolved, shall be resolved by EASI under the maintenance contract.
As part of its services, the consultant reserves the right, with the agreement of the client, to take a back-up of the database to meet a specific need of the customer (custom development, configuration test before installation, reproduction of a possible anomaly in the software.). This backup will then have to be destroyed maximum 3 months after the creation of this one.
1.4. MAINTENANCE OF STANDARD SOFTWARE DEVELOPED BY EASI
On the other hand, the signing by the customer of a maintenance contract, whether integrated or not into the contract specifying the special conditions, is obligatory for some of the software packages developed by EASI. If the customer fails to take this out or pay the related maintenance fees, it will automatically lose the right to use the software package concerned and shall be required to immediately return it, and its media, to EASI, without reimbursement of the usage licence fee. No specific maintenance contract shall be entered into when renting, the maintenance being covered by the periodic fees.
The maintenance covers, for the standard version of the software package and therefore excluding specific developments such as programs, layout and interface which do not form a part of the maintenance: (1) the correction of errors in the software package delivered, which are defined as anomalies by reference to the specifications, capacities and limits thereof, (2) adaptations to the software package in the hypothesis where it is partially or totally overtaken due to modifications in the law or regulations which were used as a reference for the development of these applications, (3) the granting of the right to use the new versions of the software package (releases), and (4) Hot Line Telephone support (excluding specific developments such as programs, layout, interfaces and reports which do not form part of the standard version) for users having taken the basic training on the software package and who have actively participated in the implementation phase with the EASI consultants. Under the maintenance contract, EASI moreover guarantees that two of its members of staff will always have an in-depth knowledge of the software package concerned.
In the case of the discovery by the customer of an error likely to be covered by the maintenance contract, it shall send a written request to EASI (via its Extranet) for a service call justified by a precise description of the error discovered and accompanied by as much documentation as possible (list, screen print, etc.). EASI undertakes to provide follow-up within a period of three working days from the receipt of a justified request for intervention, depending on its urgency and except in the case of force majeure. A shorter time period may be expressly established in one of the special provisions of the contract, including as part of any Service Level Agreement.
The maintenance does not, in any case, cover malfunctions of the software package caused by circumstances external to it and, in particular, by the following circumstances: (1) inappropriate use of the software package, (2) an error in the handling of the software package by the customer’s staff or a third party, (3) any changes made to the database by the customer or a third party, (4) the use of accessories which do not comply with any possible recommendations made by EASI, (5) problems inherent in the hardware equipment or other software packages installed by the customer, (6) defects in the electrical circuits or supply, this list not being exhaustive. All the costs incurred and the services provided by EASI with a view to remedying problems not covered by the maintenance contract shall be invoiced to the customer for settlement, at the rate in effect.
For purchase or rental contracts in the customer's infrastructure, the cost of the installation of new versions of the software package is not covered by the maintenance contract and shall be invoiced to the customer for settlement, at the rates in effect. The same applies to the cost of updating specific developments which had been, at the request of the customer, adapted as accessories to the software package, if the publication of a new version thereof involves a modification or adaptation to the aforementioned specific developments. For rental contracts in the Cloud2be environment of software packages that require an environment or specific settings by customer (EASI Financials), the periodic fee includes the cost of installation of a maximum of two new minor versions of the software package each year. The services associated with the installation of a major version of the software package shall be invoiced for settlement, at the rate in effect. For rental contracts in the Cloud2be environment of other types of software packages, the periodic fee includes the cost of installation of all new versions of the software package. In all cases, the cost of training in the new versions of the software package is not covered by maintenance and shall be invoiced to the customer for settlement, at the rate in effect.
For purchases of software packages, each maintenance contract is concluded for an unlimited period. The execution of the maintenance contract shall be suspended in the case of the suspension of the right of the customer to use the software package. The customer may terminate the maintenance contract by giving advance notice of three months which shall take effect on the date on which it advises EASI by registered mail of its decision to no longer use the software package. All annual maintenance fees, invoiced in advance, must be paid in full by the customer and shall not be refunded, even if the period covered by this licence fee exceeds the three-month advance notice period. EASI may terminate the maintenance contract in the following cases: (1) by advance notification of twelve months if it decides to no longer provide maintenance for the software package, in which case the calculation of the maintenance fees shall be done on a prorata temporis basis, (2) in the case of failure by the customer to fulfil one of its obligations if this has not been remedied within fifteen days of the issue of a formal notice by EASI, without prejudice as to the damages which it may claim, (3) without notice in the event that the customer has lost the right to use the software package by virtue of other contractual provisions applicable between the parties.
The customer shall pay EASI an advance annual maintenance fee equivalent to 25% of the list price of the software package, except in the case of rentals where the periodic fee includes the maintenance of the software package. The first maintenance fee shall be calculated prorata temporis, up until the end of the calendar year (I) from the first day of the month following the effective start-up of the software package by a transfer or systematic encoding of data or by continual operational use arising from the performance of simple one-off tests, (2) failing such start-up, from the first day of the fourth month following the project launch (Kick-off) meeting, and (3) in any case, at the latest from the first day following the end of a six-month period starting on the date of the order, up until the end of the calendar year. This portion shall be invoiced at the same time as the licence order portion, based on the estimated date of the project launch meeting as specified when the contract is signed. The second and subsequent maintenance fees shall be invoiced in the month of December preceding the year concerned. The maintenance fee shall be indexed on the 1st January of each year on the basis of the consumer price index, the basic index being that of the month of November preceding the calendar year of installation of the software package, and the new index being that of the month of November preceding adaptation. Non-adaptation of the fee on one or more of the annual indexing dates shall under no circumstances be considered as waiving the right to index the fee during the course of the year or during subsequent years.
EASI reserves the right to no longer market, no longer provide maintenance or create new versions of each of the software packages developed by it, without its decision authorising customers to claim from it any damages of any kind, provided the advance notice set out in article 33 is complied with.
1.5. SPECIFIC DEVELOPMENTS
Specific developments are set out in heading 1.5, namely (1) the complete writing of a custom-built piece of software, (2) the changes to existing software, (3) the creation of data-capturing software or interface software, (4) additional developments to EASI software packages or to one or more of the customer’s applications, and (5) the specific reports developed for the customer. Also set out in heading 1.5 are the design and the specific developments for the customer of applications for mobile devices, such as tablets and smartphones, intended either to be used internally by the customer (in house) or to be transferred, accessible and operational on platforms belonging to a third party such as, for example, Apple AppStore, Google Play Store and Windows Store. The contract in respect of a specific development is a contract work contract involving services of an intellectual nature: functional analysis, design and programming. The term "applications" used in the following articles of this section covers both the developments set out in paragraph I as well as the applications for mobile devices set out in paragraph 2 of this article.
The application is designed and produced in compliance with the specifications of the advance functional analysis. This shall be drawn up by EASI in co-operation with the customer, who is required to provide EASI with all the information which will allow it to fulfil its task of advice with a view to ensuring the appropriateness of the application to the requirements and wishes of the customer. The customer shall be required to designate a member of its staff as EASI’s dedicated contact person in the context of the functional analysis. Once this analysis is approved by the customer, it shall serve as the basis for design and subsequent programming, and as a reference in the subsequent examination of the appropriateness of the application for the requirements and wishes of the customer, as formulated in an exhaustive manner in the aforesaid analysis.
The application shall be produced using files, models, drawings, photographs and any other elements sent by the customer to EASI via various types of media. The customer guarantees that it legally holds all rights and authorisations for the use of the elements set out in paragraph I as supplied with a view to the design and development of the application. The customer shall therefore hold EASI harmless from any claims made by third parties relating to any of these components, in terms of principal, interest and costs, including legal expenses, in addition to any damages that it may be liable to pay EASI. EASI shall be authorised ipso jure to suspend the contract until a judgment has been passed on the claim made by the third party or to terminate the agreement with immediate effect. In the latter case, the customer shall be liable to pay EASI compensation equivalent to double the amount remaining to be invoiced. The customer guarantees that the elements supplied by it with a view to the design and development of the application are not likely to undermine public order, cause an affront to public decency, undermine privacy, data protection, child protection or any other mandatory provision. The customer guarantees that the same is true with regard to the use of the application, it being understood that EASI shall be authorised to terminate the agreement with immediate effect in the event of a breach of this obligation. In this case, the customer shall be liable to pay EASI compensation equivalent to that specified in the previous paragraph. EASI shall not be held liable in the event of theft, destruction or deterioration of the equipment and media supplied by the customer. The customer undertakes to insure these items against all risks, including theft, damage or destruction for any cause whatsoever, and assumes all liability therefor. EASI shall not be obliged to retain these items following final acceptance of the application, unless otherwise specified in the special conditions.
Following its analysis and development, a "test" version of the application shall be made available to the customer. From the time this "test" version is made available, the customer shall have a period of three weeks to perform tests allowing it to ensure that it conforms in all its elements to the specifications of the functional analysis, and to make any comments. The customer shall be required to devote the time and necessary means to complete these tests within the aforesaid period. In the absence of any written observation within the aforementioned period, or in the case of the starting of the application by a transfer or systematic encoding of data, or by on-going operational use resulting from the performance of simple ad hoc tests, or in the case of a request made by the customer to EASI to submit the application for validation to the owner of the platform, the application shall be irrevocably considered as finally accepted by the customer.
If the customer discovers the presence of anomalies during the test period, it shall advise EASI thereof in writing and in a precise manner, as they are discovered. At the end of the test period, EASI and the customer shall draw up, at the first request of either, a provisional acceptance report of the application indicating the anomalies to be solved, it being understood that any other anomaly existing at the date of drafting of this report which is not indicated therein cannot be subsequently evoked by the customer to refuse definitive acceptance. In the event that the customer refuses to carry out the drafting of the provisional acceptance report on one of the dates proposed by EASI, the application shall be irrevocably considered as finally accepted by the customer, even if anomalies were notified during the test period.
Final acceptance shall be given by the customer as soon as all the anomalies described in the provisional acceptance report have been resolved. However, (1) the transfer or systematic encoding of data, or on-going operational use of the application by the customer, or (2) a request made by the customer to EASI to submit the application for validation to the owner of the platform, or (3)in the case of an in-house application, the application being made available on the customer's internal server, means final acceptance and and involves the obligation for the customer to make payment to EASI of the full amount remaining due, notwithstanding the fact that, in these various cases, each of the aforementioned anomalies have not been resolved.
When the application is produced in a number of intermediary phases, each of these phases shall be accepted in a separate manner in accordance with the procedure defined above under 39.1 to 39.3, it being understood that the customer can no longer make any complaints regarding phases of the specific development which were previously accepted.
If changes or additions which were not initially planned need to be made to the application during development or during the test or provisional acceptance phase, or following final acceptance, at the request of the customer, EASI's services shall be invoiced to the customer at the hourly rate in effect. These changes or additions also include tasks that are necessary to adapt the application to new versions of the operating system, new features in the operating system or new devices, that were not yet available on the market where EASI's headquarters were situated at the moment of the signature of the contract. The same applies for any services that enable the obtaining, after final acceptance of the application, of validation by the owner of the platform, where this it has been refused for reasons not attributable to EASI; some of these reasons are specified in article 40.3, for illustrative purposes.
The applications produced by EASI , that do not need to be published on a third party platform (for example the Apple Appstore, Google Play, Windows Store), are guaranteed for a period of one month with effect from the date of final acceptance. The applications produced by EASI , that have to be published on a third party platform (for example the Apple Appstore, Google Play, Windows Store), are guaranteed for a period of seven days with effect from the date of the publication in the concerned store. The guarantee only covers programming errors with the express exclusion of all complaints directly or indirectly related to the advance analysis or design. The guarantee consists of the correction of errors and EASI shall be required to intervene only on written request made by the customer, justified by a precise description of the error or errors discovered and accompanied by as much information as possible (list, screen print, diagrammatic reproduction etc.). EASI shall intervene within a period of three working days from the receipt of the written request, depending on its urgency and except in the possible case of force majeure.
The guarantee particularly excludes malfunctions resulting from circumstances external to the application and, in particular: (1)inappropriate use of the product, (2) handling errors committed by the customer’s staff or a third party, (3) repairs, maintenance work, modifications, adaptations or moving carried out by persons who are not EASI personnel, (4) problems inherent to the customer’s computer hardware equipment or other software, (5) the use of accessories which do not comply with EASI specifications, (6) modification or adaptations, even minor, made by the user or third parties to any of the programming elements supplied by EASI, (7) handling of sources, (8) deficiencies in the electrical installation or electrical supply, without this list being exhaustive. At the end of the guarantee period, EASI shall not longer be required to intervene or make indemnification of any kind for any reason. Any intervention by EASI after the expiry of this period shall be invoiced for settlement, at the rate in effect.
For applications which need to be made available on third-party platforms, both during development and once the application has been developed and accepted according to the terms set out in articles 39.1-39.5, EASI shall under no circumstances be responsible in the event of a problem being found with the platform or its owner for reasons which are not attributable to EASI (for example, refusal of access or obligation to exit, particularly for non-compliance with the platform regulations, transfer or maintenance on the platform on various changes, increase in costs, disappearance, malfunction or overloading of the platform, pirating, misappropriation etc.). EASI shall be solely responsible in the event that the owner of the platform refuses to validate the application because the source code does not comply with its regulations; in this case, EASI shall bear the costs of any adaptations required to obtain validation. EASI shall under no circumstances be responsible for messages sent by the customer to third parties from its servers or from servers belonging to EASI, including as part of the automatic message notification services (Push services).
The price of specific developments includes the cost of the analysis (collection of data on the customer’ premises, drafting the analysis, design of the print and presentation of the analysis), design and programming (writing the programs, execution of pre-installation tests). The price does not include (1) the cost of installation of the applications on the customer’s system, (2) the costs of training the customer and its personnel, and (3) any additional costs.
Fixed-rate projects which are expected to take less than 24 calendar days shall be invoiced at 100% on ordering. Projects which are expected to take longer than 24 calendar days shall be invoiced at 30% on ordering, 30% during analysis, 30% on delivery and installation and 10% on final acceptance.
The customer shall be granted a licence for the use of the application designed and developed by EASI. The methods, models, descriptions, calculations, specifications and know-how relating to the application as well as its source code shall remain the exclusive property of EASI and shall not be made available to the customer. Therefore, unless specified otherwise: EASI shall remain the exclusive owner or holder of a licence for the use of all intellectual property rights associated, directly or indirectly, therewith; the source code of the applications shall never be given to the customer; the provisions of article 24 of these general conditions shall be apply mutatis mutandis to the applications specified in this heading; and the intellectual property rights of EASI shall apply not only to the initial application and its source code but also to all subsequent corrected, adapted or improved versions.
1.6. MAINTENANCE OF SPECIFIC DEVELOPMENTS FOR MOBILE DEVICES (SMARTPHONES, TABLETS ETC.)
The customer shall take out an application maintenance contract specifically for mobile devices.
Maintenance covers the updating of the application.
EASI undertakes, on the one hand, to regularly monitor the development of the operating systems and/or mobile devices (devices such as tablets and smartphones), to examine whether this development requires an update to the application or not, and, where it does, to provide the technical services enabling an update to be performed.
Updates mean only those services required for the operability of the application with the operating systems and mobile devices enabling its use and launched on the Belgian market later than that date on which the application was placed online for the first time, but only for the platform(s) chosen by the customer when the agreement on the design and development of the application is signed. An evolving and exhaustive list of the mobile devices for which an update is envisaged as part of the maintenance contract may be consulted at any time on the EASI site, it being understood that no update on mobile devices other than those indicated in this list may be demanded by the customer as part of the maintenance contract.
Updates shall only involve maintaining the existing functionality of the application at the time of its acceptance and not the possibility to use one or more of the new functionalities offered by the new mobile devices or envisaged following adaptation of the platforms and operating systems.
EASI undertakes to inform the customer of the update performed.
The maintenance does not cover the following cases:
- the owner of the platform adopts a new version of the operating system and, in order to maintain the application, it needs to be modified so as to make it compatible with this new version.
- the customer wishes to make changes to the application and the application must therefore be compatible with the new operating system and for this purpose be re-validated by the owner of the platform.
The maintenance contracts shall be entered into for successive periods of one year with effect from the date of the transfer of the application to the chosen platform(s). Each party may terminate the contracts by registered letter sent to the other party three months before the expiry of the annual period. The fee paid by the customer to EASI for the maintenance of the specific application shall be indexed on 1st January of each year based on the consumer price index, the basic index being that of the month of November prior to the calendar year in which the application is made available in accordance with article 39.1, the new index being that of the month of November prior to the adaptation. The non-adaptation of the fee on one or more of the annual indexing dates may under no circumstances be considered as waiving the right to index the fee during the course of the year or during subsequent years.
1.7. CLOUD HOSTING SERVICE - CLOUD2BE
This heading 1.7 sets out the option for the customer to rent the EASI infrastructure in order to house all of its data and applications, aside from the EASI software packages specified in heading 1.7, in return for payment of a periodic fee, the amount of which shall be fixed depending on the technical capacity requested, which may be flexible according to the terms specified by the special conditions of the agreement entered into between EASI and the customer.
The infrastructure and particularly the EASI servers enabling the use of the software by the customer in a "Cloud" environment shall be installed by EASI in a secure place (data centre) of its choice, where EASI shall have its own racks and servers. EASI shall have the right to transfer these infrastructures to any other secure building of its choice, without this transfer authorising the customer to terminate the agreement without providing the agreed notice. The customer shall remain the owner of its personal data stored on the EASI installations and shall have the right to access this date remotely or to recover it any time by paying EASI all of the outstanding amounts owed. The services carried out to recover the data shall be invoiced to the customer, at the rate in effect. In the event that the customer does not pay EASI the amounts owed, EASI shall have the right to suspend access to this infrastructure in the "Cloud" environment as well as the return of the data for as long as all of the amounts owed to EASI by the customer remain unpaid.
EASI guarantees 99.75% availability of the infrastructure per month, it being understood that the following shall not be taken into account when calculating this percentage: planned maintenance ( in theory, four windows of 24 hours of maintenance per year planned over weekends), as well as any disruptions not attributable to EASI (including network outages associated with Internet service providers). EASI shall only be held liable by the customer from the time that EASI is directly responsible for the cause of any unavailability. The amount of any penalties in the event of unavailability attributable to EASI as well as their method of calculation or conversion into hours worked shall be specified in the special conditions of the contract entered into between EASI and the customer but shall under no circumstances exceed 10% of the fee calculated on an annual basis.
EASI guarantees the confidentiality of the customer data stored at its premises as well as the strict respect of all personal data forming a part thereof.
The contracts for hosting services shall be entered into for an indefinite period with a minimum of three years. During this period, the customer shall have the right to terminate the agreement by registered letter giving three months' notice from the 1st of the month following its acceptance by EASI and through payment of an indemnity depending on the duration of the contract which shall be specified in its special conditions. The indemnity shall be calculated with reference to the initial fee, indexed where applicable. If the hosting services agreement is not terminated three months before the end of its initial term, it shall be tacitly renewed for annual periods of one year, each party having the right to end the agreement by sending a registered letter to the other party at least three months before the annual expiry date of the agreement.
At the end of the hosting services agreement, the customer data shall be returned in the form of a backup on backup media and, in order to guarantee confidentiality, EASI shall not retain any copy thereof. The services carried out to recover the data shall be invoiced to the customer, at the rate in effect.
1.8. USE OF EASI SOFTWARE PACKAGES IN THE CLOUD ENVIRONMENT
This heading 1.8 sets out the option for the customer to use one or more EASI software packages in a "Cloud" environment. The installation of EASI software packages in a "Cloud" environment shall be authorised solely in the EASI "Cloud2be" environment.
In this case, the monthly fee paid by the customer shall include:
- a licence component for "rentals" as set out in article 25 of these general conditions
- a maintenance component in a "Cloud" environment similar to that specified in article 30
- an infrastructure component (the rental of space and power on the EASI servers, the use of the bandwidth between the EASI and Internet software as well as updates and hardware upgrades)
- a service component (including security, monitoring of the infrastructure, performance analysis of the performances etc.) according to the details provided in the special conditions.
The costs of the communication between the infrastructures made available to the customer and the equipment of users authorised by the customer shall not be included in the fee and shall be borne entirely by the customer, it being understood that the customer shall be responsible for ensuring that it has the necessary and sufficient bandwidth for accessing the Cloud infrastructures via Internet.
This heading applies to the services executed by EASI in the context of specific assistance sought by the customer independent of all supply of hardware and software covered by the preceding headings. This assistance shall include, without this list being exhaustive, advice services and training services. The purpose of this assistance shall be defined in the special agreements made between EASI and its customer.
The agreed services shall be executed by an associate, employee or sub-contractor of EASI, who may replace this person at any time, without the customer being able to object to this, even if the identity of the associate is specified in the special conditions of the contract. The EASI employee shall execute the assistance task while remaining under its authority but while taking account of the information and directions given by the customer. Any instruction given by the customer to the EASI employee with regard to welfare at work, working time and resting time, and any instruction in relation to the execution of the agreed assistance, shall not constitute the exercise of authority on the sense of article 31, paragraph 1 of the law of 24th July 1987 on temporary work, temporary working and the provision of workers to users. The customer shall be required to provide the EASI employee with appropriate premises, equipped in such a way as not to cause any inconvenience or discomfort in the normal execution of the agreed assistance.
The responsibility for the project for which the agreed specific assistance is required falls exclusively to the customer, in such a way that EASI shall not under any circumstances be responsible for errors or damage of any kind, insofar as the agreed assistance is considered as having been executed under the indications and directions of the customer. As regards the execution of these indications and directions, the customer accepts that it is, so to speak, impossible in the IT sector to fulfil, on every occasion, the wishes expressed and, in particular, to find a solution to every problem posed, so that, in the context of agreements in relation to specific assistance, EASI is only bound by an obligation to do its best.
Services are invoiced for settlement at the end of the month in which they were executed. When services are performed ‘on site’, the minimal invoicing period and the unit of invoicing is a half-day (4 hours and, beyond 8 hours per day, the minimum unit of invoicing is an hour), even if the services performed were less. Services and support by phone or remotely are invoiced at a minimum of, and with a minimum unit of invoicing of, 1/4 hour. Services provided outside normal office hours (before 8.00 a.m. or after 6.00 p.m.) and on weekends or public holidays, shall be taken into account, for public holidays at 200% of the rate in effect, and for the other days and times mentioned above, at 150% of this rate, in addition to associated costs. Services exceeding eight hours in one day shall also be invoiced at 150% of this rate. At the end of the month, a total statement of the hours of service provided during that month shall be sent to the customer. The hourly rates are indexed each year, on 1st January, based on the consumer price index, the basic index being that of the month of November 2013, the new index being that of the month of December preceding the revision date. Non-indexation on the annual date agreed shall not imply waiving of the right to apply indexing during the year or on subsequent annual dates.
Co-sourcing assignments of 1-24 days per year are invoiced in advance, at the beginning of each year. Co-sourcing assignments of 25-48 days per year are invoiced half-yearly in advance, at the beginning of each half-year period. Co-sourcing assignments of 49 days and more per year are invoiced per quarter in advance, at the beginning of each quarter. Services provided as part of a co-sourcing assignment shall be deducted from the number of days specified in the contract. ‘On site’ service calls are invoiced per hour, with a minimum of 2 hours, even when the services performed were less. Telephone or remote support are invoiced per ¼ hour. Co-sourcing assignments outside of office hours and not on working days as well as those over eight hours a day shall be invoiced using the same terms using set out in article 53.1, where necessary in addition to the amounts already invoiced in accordance with the previous paragraph. The fee paid for co-sourcing contracts shall be indexed on 1st January of each year based on the consumer price index, the basic index being that of the month of November preceding the calendar year in which the contract starts, the new index being that of the month of November preceding adaptation. Non-adaptation of the fee on one or more of the annual indexing dates shall under no circumstances be considered as waiving the right to index the fee during the course of the year or during subsequent years. The customer may terminate a co-sourcing contract by giving notice one month before the contract expires. Any co-sourcing fee invoiced in advance shall be fully paid by the customer and shall not be refunded.
Fixed-price projects of less than 24 calendar days in duration are invoiced 100% at the time of the order. Fixed-price projects of a planned duration of over 24 calendar days are invoiced at 30% at the time of the order, 30% during the analysis time, 30% upon delivery and installation and 10% upon final acceptance.
Standard training sessions are invoiced in full at time of the order. The customer can still cancel its participation, in writing, up to 10 working days before the start of the training. Once this period has passed, the total invoiced amount is due. No credit, return or partial return of the subscription costs for the training will be granted. The customer may then let an associate replace it at the training session, or take part in another, later, session, provided that the registration cost is less than or equal to that of the session it did not attend, without any entitlement to a refund of the difference in price.
If the customer is not satisfied with the assistance provided by the EASI employee, it shall advise EASI thereof, in writing, on the same day, in order that EASI can take all appropriate measures in the event that it considers the reasons given are founded. In this case, EASI shall have the facility to entrust the assistance from the customer to another member of staff, or to end this assistance without requirement to pay any compensation of any kind. A customer who is required to communicate the reason for its dissatisfaction to EASI on the same day on which this dissatisfaction is found cannot invoke this for refusing to make payment for the services executed by the member of staff during the previous days. The same shall apply if EASI decides to replace the member of staff or to end all assistance.
2. Processor Agreement for the Processing of Personal Data
The purpose of this agreement is to define the conditions under which the processor undertakes to carry out, on behalf of the controller, the personal data processing operations defined below.
Pursuant to their contractual relations, the parties undertake to comply with the regulations in force applicable to personal data processing, and in particular Regulation (EU) 2016/679 referred to in the recitals of this agreement.
The processor shall be authorized to process, on behalf of the controller, the personal data needed to provide the following services:
Please describe the services EASI is delivering to this particular customer. You can find some examples hereunder: )
- Data hosting in Data Centres managed exclusively by the processor (Cloud2be/Safe2be/INTO Cloud), or solutions hosted by third parties, e.g. , but not limited to, Microsoft, Google, Amazon, and so on.
- Data backups in Data Centres managed exclusively by the processor, as described in the latter’s backup policy.
- Support on premise data environments.
- One-shot installations from a NAS, IBM Power I, …
- Remote support on applications like Adfinity, SmartSales, SmartShare, SmartDrive, …
Data stored in EASI’s applications (for example SmartSales, SmartShare, Adfinity, SmartDrive) are examples of data mentioned here above.
The purposes of the processing are based on the main contract between the processor and the controller.
For the provision of the service which is the subject of this contract, the controller might provide the processor with additional information.
The processor shall be entrusted no assignment other than that which consists of storing and backing up the data.
This agreement shall enter into force as of the signing of the contract and shall expire on the same date as the main contract referred to in the recitals.
The processor undertakes to process the data for the sole purposes which constitute the object of the processor agreement, i.e. exclusively their storage and backup.
The processor undertakes to process the data in accordance with the controller’s documented instructions.
If the processor considers that an instruction constitutes a violation of the European general data protection regulation or any other provision of EU law or the law of the Member States relating to data protection, it shall inform the controller immediately.
Furthermore, if the processor is required to proceed to a transfer of data to a third country or an international organization, by virtue of EU law or the law of the Member State under which it falls, it shall inform the controller of this legal obligation before processing, except if the law concerned prohibits such information for important reasons in the public interest.
The processor undertakes to guarantee the confidentiality of personal data processed under this agreement.
It shall moreover ensure that the providers of services or members of its staff who intervene in the storage and backup of personal data under this agreement:
- are not entitled to process the data themselves;
- undertake contractually to observe confidentiality or are subjected to an appropriate legal obligation of confidentiality;
- are given the training needed on personal data protection and the importance of complying with privacy protection legislation;
The confidentiality commitments undertaken by virtue of this agreement shall persist during the entire term thereof as well as for two years as of its expiry date.
The processor shall finally take into account the data protection principles concerning its tools, products, applications or services, as of the design and protection of data by default.
The processor may call on another processor, hereinafter referred to as the “subsequent processor,” for specific processing activities.
In such a case, it shall inform the controller in writing in advance of any planned change concerning the addition or replacement of other subsequent processors.
This information must indicate clearly the sub-contracted processing activities, the identity and details of the subsequent processors, and the dates of the subsequent processor agreement.
The controller shall have at least fifteen/thirty days as of the date this information is received to present its objections.
This sub-contracting may be carried out only if the controller has raised no objections during the agreed period.
The subsequent processor shall be required to comply with the obligations of this agreement on behalf and according to the instructions of the controller.
The initial processor shall ensure that the subsequent processor provides the same sufficient guarantees concerning the implementation of appropriate technical and organizational measures, so to that the processing meets the requirements of the European general data protection regulation.
If the subsequent processor fails to meet its data protection obligations, the initial processor shall remain fully liable to the controller for the fulfilment by the subsequent processor of its obligations.
It shall be up to the controller to provide information to the data subjects concerned by the processing operations when data are collected.
The processor shall insofar as possible help the controller fulfil its obligations to respond to requests by data subjects to exercise their right to access, correct, delete and oppose, limit the processing, the right to data portability, not to be subjected to automated individual decision, including profiling.
When the data subjects file requests to exercise their right with the processor, the latter shall upon receipt forward them by e-mail to the contact indicated by the controller.
The processor shall inform the controller by e-mail of any violation of personal data within twenty-four hour maximum of becoming cognizant thereof.
Said notification shall be accompanied by any useful documentation to enable the controller to report this violation to the competent authority as and where necessary.
It will then be up to the controller to notify the personal data violations detected to the competent authority and apprise the data subject accordingly as promptly as possible, unless the violation in question is likely to entail a risk for the rights and freedoms of said person.
The reporting to the competent authority and notification of the data subject shall include all information required by the European general data protection regulation.
The processor undertakes to take appropriate technical and organizational measures in view of the risks inherent to the processing and nature of personal data.
He shall in particular take measures to:
- prevent unauthorized persons from accessing the IT systems that process personal data so that they cannot consult, reproduce, edit, delete or disseminate them;
- guarantee that the authorized users of data processing systems can access only personal data covered by their access rights;
- prevent personal data from being read, copied or deleted when transmitted or transported on storage media;
- guarantee the confidentiality, integrity and availability of processing services,
- restore the availability of personal data and access thereto within appropriate time limits in case of physical or technical incident;
- assess regularly the effectiveness of technical and organizational measures to ensure processing security.
Under this agreement, the processor shall, according to the controller’s choice:
- destroy all the personal data; or
- return all the personal data to the controller, or
- return the personal data to the processor designated by the controller.
The controller shall inform the processor of its choice within fifteen/thirty days of the term of this agreement, otherwise all personal data shall be destroyed, without any recourse on the part of the former against the latter.
Such return shall be accompanied by the destruction of all copies in the information systems of the processor, who shall justify the destruction in writing.
The processor shall provide the controller with the contact details of his data protection officer, if it should appoint one pursuant to Article 37 of the European general data protection regulation. The data protection officer of the processor can be contacted via email@example.com.
The controller shall undertake to:
- provide the processor with the information referred to in chapter II of this agreement
- document in writing all instructions concerning the processing of data by the processor
- ensure beforehand and during the entire term of the processing compliance, including by the processor, with the obligations stipulated by the European general data protection regulation;
- supervise the processing.
The processor shall be held liable for damage caused by the processing entrusted to it only if it failed to fulfil the obligations stipulated in the European general data protection regulation incumbent specifically on the processors or if it acted outside or contrary to the legal instructions of the controller.
It shall be absolved of any liability if it proves that the event which caused the damage can in no way be attributed to it.
Neither of the two parties shall be liable to the other for a delay or failure to fulfil its contractual obligations due to one or more reasons beyond its reasonable control, in particular natural disaster, decision of public authorities, war, fire, flood, explosion and civil unrest (the list is not exhaustive).
Provided that the party that incurs the delay informs the other party rapidly and in writing of the reason and probable length thereof, the fulfilment of its obligations shall be suspended insofar as said obligations are influenced by the delay, for the period during which the reason for the delay persists.
Neither party may transfer the rights and obligations arising out of this agreement without the prior, written consent of the other party, which shall not refuse nor delay granting such consent without reasonable grounds.
Any amendment to this agreement shall necessarily be in writing, signed by the person vested with the relevant powers.
This agreement shall be governed by Belgian law.
Any dispute as to the validity, interpretation, performance, cancellation or termination shall be referred exclusively to the courts of the processor’s registered office.
The processor may nonetheless call upon the controller for intervention and guarantee before any other court in charge of ruling on a main action which justifies the involvement of the controller.